Y--Rehabilitate Buildings at Boston National Historic

The solicitation seeks a single contractor to rehabilitate designated historic buildings in Boston, performing all site‑mobilization, façade and roof access, and construction activities in strict accordance with the drawings, specifications, and historic‑preservation requirements. The contractor must coordinate with the City of Boston and the National Park Service to obtain all necessary permits, provide continuous access for the Contracting Officer, and adhere to product‑matching specifications (including visual‑matching to architect samples) or submit approved substitutions. A comprehensive technical approach is required, detailing sequencing, scheduling, quality‑control reporting, risk identification and mitigation (including material lead‑time and tariff volatility), and a Gantt‑style schedule showing the critical path, permitting milestones, and contingency allowances. The offer must include a detailed storm‑water pollution prevention plan and a Unified Pollution Prevention Plan (UPPP) that meets NPS standards, as well as all required certification, notice, and record‑keeping forms. Offers must be sealed, submitted in original and electronic copies, include an offer guarantee, and be accompanied by any required performance and payment bonds within the specified calendar days after award. The proposal must be organized into electronic folders for each evaluation factor (Technical Approach, Project Experience, Management Experience, Past Performance, Price) and must meet all solicitation terms, conditions, and technical requirements to be considered for award.

Notice ID

880829c9ff2645ffad3ad2eb655f425b

Solicitation Number

140P4326R0021

NAICS Code

236220

Classification Code

Y1JZ