Multiple Building Flooring Repairs

The Navy’s Marine Corps Base Camp Lejeune is issuing Solicitation N40085‑26‑R‑9028 (Project 24‑0419) for “Multiple Building Flooring Repairs” across three buildings. The contract, with a 360‑day performance period and an estimated value of $500,000‑$1,000,000, will be awarded to the lowest‑priced responsive offer. Offerors must price all three ELIN line items (ELIN 0001‑0003) and include full overhead, labor burden, and profit; failure to submit a price on any line item will be considered non‑responsive. The work must be performed while the facilities remain fully operational, requiring the contractor to minimize interference with normal activities. One qualified individual may serve simultaneously as Superintendent, Quality‑Control Manager, and Safety & Health Officer. Daily reporting must include weather conditions, detailed labor and trade lists, safety actions, inspections, and any incidents (e.g., lost‑time accidents, hazardous material releases) with supporting documentation. Compliance with the FAR 52.225‑9 “Buy American‑Construction Materials” clause is mandatory, and offerors seeking a determination of inapplicability must submit the required data to the Contracting Officer before offer submission. Liquidated damages are assessed at $880 per calendar day for late completion.

Notice ID

cce0ba8b07964f08a6424288049e22fd

Solicitation Number

N4008526R9028

NAICS Code

236220

Classification Code

Z2JZ